Have you encountered the situation whereby the delay of the construction work is solely due to the delay of the project owner ‘’Employer? You as the contractor, do you need to apply for Extension of time though the delay is not due to your fault.
Whenever there is delay in the construction works, contractor always can exercise their right under the contract to ask for extension of time. However, before to exercise such right, the contractor must then fulfil the condition precedents stated in the standard form contract.
Clarification Notice | 澄清文告 中文 한국어 To whom it may concern, We refer to the more than 50 calling to our law firm Managing Partner Mr Ng’s mobile phone number 011-6933 0650 by unknown person who condemned that our this legal firm mobile firm which belongs to Mr Ng has been used by an irresponsibility …
Recently a judgement regarding a issue of a mother who get married in overseas and having a foreigner husband….
Pupils In Chamber Vacancy – BY MESSRS. NG KEE WAY & CO.
Location: Bandar Puteri, Puchong, Selangor.
Requirement:
Possesses Microsoft Word, Powerpoint and Excel skills.
Ability to draft and review documents in English and Bahasa Malaysia.
Experience or knowledge in Malaysian divorce, company and employment laws is helpful, but not mandatory.
Candidate must possess a Bachelor’s Degree in Law or equivalent.
In construction industry, non-payment or delay in payment is a “norm”. When facing such a situation, normally contractors tend to slow down their works or suspend their works until payments are paid by the employer. It is a fact that each contractor has a deadline to complete the works.It is undeniable that no contractor would like to advance their own fund to finance the construction project on behalf of the employer. Bear in mind that once the employer failed to make the payment, the employer in fact has breached the agreement/letter of award.
What if you didn’t get your payment when you have supplied goods to the contractors or you have done the construction works? In Malaysia, there are many contractors/suppliers facing collections issues whereby they have supplied goods to the contractors or done the construction works yet no payment made to them.
Congratulation to our Partner, Lawyer Khoo who is proudly announced as Asian Legal Business Malaysia Rising Stars 2022. ALB Malaysia Rising Stars 2022 is a list that showcase 25 lawyers in Malaysia who are under 40 years of age currently doing high quality work, and in progress earning accolades from their colleague, superior and clients.
Messrs. Ng Kee Way & Co. would like to take this chance to express our gratitude to our clients and ALB for this recognition.
Our Managing Partner, Lawyer Ng Kee Way (Edward) is one of the finalists for ALB Malaysia Law Awards 2022 Managing Partner of the Year.Lawyer Edward Ng’s leadership and accomplishments are always an inspiration to us. We are very proud to have an incredible leader like him. Messrs. Ng Kee Way & Co. would like to take this chance to express our gratitude to our clients and ALB for this recognition.
We are pleased to inform that our law firm has won Litigation Law Firm of the Year in Malaysia – Ng Kee Way & Co. in Global Law Experts 2022 Annual Awards.
0
